‘UPDATED: 9/4/2024
Terms and Conditions
These terms and conditions (the “Terms and Conditions”) govern and apply to all Sport Surfaces LLC customers, any associated websites, mobile sites or applications, products, and other services (collectively, the “Services”). These Terms and Conditions apply to any use of the Services.
The Services are owned and operated by Sport Surfaces LLC. While using the Services, please be aware that your access to and use of the Services and any information or documents offered by Sport Surfaces LLC are subject to these Terms and Conditions. If you choose to continue to use or access the Services after having the opportunity to read these Terms and Conditions, you are indicating your acceptance of the Terms and Conditions and Sport Surfaces LLC Privacy Policy.
If you do not agree with any part of these Terms and Conditions or Sport Surfaces LLC Privacy Policy, you must not use the Services. Sport Surfaces LLC reserves the right to modify these Terms and Conditions at any time without notice, and such changes shall be deemed effective immediately upon posting of the modified Terms and Conditions. You should regularly review these Terms and Conditions to ensure that you are aware of, understand, and accept any changes made. Your continued use of the Services following the posting of changes to these Terms and Conditions will indicate your acceptance of those changes.
THE SERVICES ARE NOT INTENDED FOR USE OR ACCESS BY ANYONE UNDER THE AGE OF 18. IF YOU ARE UNDER THE AGE OF 18, YOU MAY NOT USE OR ACCESS THE WEBSITE OR PROVIDE US WITH ANY PERSONALLY IDENTIFIABLE INFORMATION. You may not use the Services and may not accept these Terms and Conditions if (1) you are not of legal age to form a binding contract with Sport Surfaces LLC, or (2) you are a person barred from receiving the Services under the laws of the jurisdiction in which you are resident or from which you use the Services.
Authorization to Proceed & Contract
“Customer” as used herein shall refer to the homeowner, community association, and/or management company. Any and all contractual agreements made by the Customer shall be fully binding and cannot be subsequently modified or superseded by reason of a change in Customer Board Members, management company, or its employees, absent the written consent of the contractor.
“Contractor” refers to Sport Surfaces LLC, their agents, servants, employees, and/or subcontractors. Contractor shall furnish all supervision, labor, specified materials, and equipment necessary to complete the agreed upon work for the named property per this proposal. Contractor may substitute any material specified in the proposal as long as it is of equal quality. Customer shall designate one individual to represent the owner(s) in all matters pertaining to the work as it progresses. Any situations or problems which may arise shall be negotiated only between that designated representative and contractor. When working for an association, corporation, or other business entity, Contractor will not negotiate directly with any homeowner, resident, or tenant at any time, under any circumstances. Customer will ensure interference by unauthorized individuals will be avoided so as not to impede the smooth progression of the work.
Customer shall grant the Contractor permission to work in the subject area(s) and shall be required to prepare all work areas so as to be safely accessible and acceptable to Contractor. Depending on the scope of the work, Contractor may have to enter the property using a small pickup truck, skid steers/pavers, all the way to large tri-axle trucks weighing in excess of 20,000 lbs and will require stable access for our equipment. Contractor is not responsible for damages to driveway, grass, pavers, and any other areas required to enter said property for the purposes of construction. Please note that our technicians take great care to minimize this damage. Signage is recommended to more effectively mark the construction area. The Contractor is not responsible for underground utilities that are not marked or underground pipes that may be crushed/damaged while accessing the construction area. Customer must provide water, electricity, and all necessary hookups at no cost to the Contractor as deemed necessary to perform the work. The Customer shall be responsible for ensuring that all landscaping, grass, and shrubs outside the surface perimeter are lower than the surface itself to aid in proper drainage. In order to drain properly, outdoor courts require a 1” minimum slope per 10’. The Customer shall keep all irrigation systems off during resurfacing work and for 2 days following the completion of work. Damage due to use of any irrigation system will be billed as an additional expense to the Customer. Note: irrigation water may have negative effects on the new surface and should be adjusted to keep water off the court’s surface. Irrigation water will typically stain or discolor court surfaces.
It is understood and agreed that all work is performed “weather permitting”. Contractor will make every effort to timely notify the customer if work is unable to be performed due to weather. In the event the customer cancels or postpones a scheduled day’s service without providing Contractor at least 48 hours’ notice, the customer agrees to an additional mobilization fee of $475.00.
If required, this proposal does not include the cost of permit fees, engineering, drafting, blueprints, inspection fees, impact fees, or any other fees which may be required from the various agencies or municipalities having jurisdiction. Such fees, if required, are billed as incurred, and any required ancillary fees will be billed in addition to the cost of the actual permit.
Change orders, additions, or extras requested by the customer, contractor, or municipality will be invoiced as an addition to the base contract and shall not delay payment of the original contract sum.
Contractor shall not be liable for damages which are preexisting as of the date of commencement of the work to be performed under the contract. Damages can include but are not limited to people, pets, wildlife, vandalism, etc. To this end, Contractor will inspect each area prior to commencement of work in that area. The Contractor accepts no responsibility for repairs done by anyone other than Sport Surfaces LLC.
Existing damages, if any, will be noted and documented by photographs and/or written form. Customer understands and agrees that areas of unforeseen damaged or delaminated coatings and/or substrates/surfaces may be evident and disturbed during the operation and agrees to hold harmless the contractor from any and all liability in the event existing coatings, caulking, sealants, substrates, or surfaces shall peel, flake, delaminate, or otherwise affect the newly surfaced area. Furthermore, areas of aesthetic, profile, or texture differences will remain or may become more obvious with the removal of existing coatings, caulking, sealants, or substrates. The absence of a vapor barrier or curing agent on concrete or topical waterproofing agents added to the concrete voids any warranty implied or expressed in writing or otherwise.
Contractors Note Regarding Crack Treatment:
Cracks in a playing surface can be caused by many reasons. However, the most common are surface cracks & structural cracks. Surface cracks are caused by the aging surface material that becomes brittle and causes surface cracks that are generally small in width. The structural type of crack is caused by subsurface settling and is generally wider. They extend from the subbase into the aged playing surface and are caused by subsurface settling and an aged playing surface which then causes a wider deeper crack formation. This proposal includes a scope of work designed to treat the cracked areas; however, they may reappear in the same area at any time or form in new areas at any time. When these issues occur, it is not under warranty. If total elimination of cracks is desired, total reconstruction may be required. Please speak to your Sport Surfaces licensed and certified professional to discuss this option.
Contractor shall require a staging area for equipment and materials to be stored on site, and the Customer will make every effort to provide such an area. At the end of each workday, all equipment, supplies, vehicles, etc., shall be returned to that area and the actual working area left clean to the maximum extent possible. Protection of this storage area is the sole responsibility of the Contractor and shall be undertaken in a clean, safe, orderly, and acceptable manner. The Contractor is not responsible for trafficking, paint tracking, or damage to contracted surfaces due to persons trespassing in designated work areas.
The Customer will furnish stable access to the site for equipment and material. PLEASE NOTE: DEPENDING ON THE TYPE OF PROJECT WE MAY ENTER WITH LARGE TRUCKS WEIGHING IN EXCESS OF 20,000 LBS AND REQUIRE STABLE ACCESS. DAMAGES TO DRIVEWAY, GRASS, AND ANY EGRESS REQUIRED IN ORDER TO PROVIDE SERVICES WILL BE THE CUSTOMER’S RESPONSIBILITY TO REPLACE. OUR OPERATORS WILL DO OUR BEST TO MINIMIZE DAMAGE BUT SOME DAMAGE IS UNAVOIDABLE DUE TO THE SHEER WEIGHT OF OUR EQUIPMENT. The customer must provide a clean water supply and electrical feed at the job site within 100’ for construction use.
Unless otherwise specified, the repair of root-damaged asphalt is not included. Should our field technician discover such root damage, repairs will be made at an additional charge of $12.00/sf of the area repaired.
The Contractor accepts no responsibility for acts by anyone at the job site except for those subcontracted or employed by Sport Surfaces LLC. The Customer shall keep all sprinkler systems off during resurfacing work and for 1 day following the completion of work. Damage due to the sprinkler system will be billed as an additional expense to the owner.
The Contractor shall be solely responsible for the repair or replacement of any damage caused by its employees or by the materials used to perform the work contracted. Contractor has the first right of repairing or replacing a damaged area caused by the Contractor’s employee. The Customer agrees to provide Contractor with notice of the discovery of any damaged areas within 24 hours. If Contractor assumes responsibility for such damages, Contractor reserves the right to make its own repairs or to hire an appropriate other contractor to do so. Damage caused by contact with irrigation, electrical, and utilities is to be repaired by the Customer at their sole expense. Contractor is not responsible for damage to underground utilities, i.e., water, sewer, irrigation, electrical, or any landscaping or sod. This Contractor makes no warranty that after the work is completed all standing water will be eliminated. The customer understands and agrees that small depressions and standing water may still occur in any area of the court surface(s).
Re-mobilization fee:
If production is halted due to circumstances beyond our control, permit issues, or failure to receive progress payments, a $500 re-mobilization fee shall be charged to pay for crew downtime, gas, and expenses.
The Contractor shall thoroughly and expediently clean up all debris, materials, drums, trash, etc., upon job completion. Clean-up will be conducted on-site, and a wash-down area is required to rinse squeegees, brooms, and containers. Contractor will do its utmost to protect the surrounding areas; however, Contractor is not responsible for any paint residue that may remain in any wash-out areas. Please note that the grass on the staging area may become damaged, and we are not responsible for sod replacement as it is nearly impossible to prevent and sod replacement was not included in our estimates.
If a dispute arises over any aspect of this contract, prior to the commencement of any civil litigation, the Customer agrees to participate in one session of mediation to attempt to resolve such dispute. The cost of the mediation shall be borne 50-50 between Contractor and Customer. This provision SHALL NOT be binding upon Contractor if the matter pertains to the collection of any unpaid invoice(s). Should any of the provisions of this Agreement be found to be void for any reason, only such void portions shall be unenforceable, and the remaining conditions or portions thereof shall remain in full force and effect. Venue for any litigation that may arise shall be Palm Beach County, State of Florida.
If it becomes necessary for the Contractor to hire an attorney to enforce any provision of the contract, including the collection of unpaid invoices, the Contractor shall be entitled to recover from Customer all its court costs and reasonable attorney’s fees incurred prior to suit, as well as in litigation, appeal, and in any bankruptcy or administrative proceedings.
OUT OF STATE PROJECTS
Clients in states other than Florida and New Jersey are required to pull all permits should they be required. All communication with the building department will be the customer’s responsibility to deal with any permitting issues directly with the local building department. Any permitting issues will be exclusively the customer’s responsibility, including any costs associated with re-mobilization due to permit issues or stop-work orders.
FINES / TICKETS
Many communities’ HOA’s and board of directors have intricate by-laws that include but are not limited to parking fines, weight restrictions, and other restrictions that could potentially lead to fines against Sport Surfaces or our associates. Should any fines be levied against Sport Surfaces or its associate, they will be paid for by the customer.
WARRANTY
Warranty is non-transferable and only covers the original owner. The warranty shall become void should payment terms not be met. A maintenance manual for hard courts is available online at sportsurfaces.com and must be followed along with a yearly inspection to keep the warranty in effect. Inspections can be scheduled at warranty@sportsurfaces.com. Please note that debris from trees, dirt, chemicals, and other deleterious materials can cause extensive damage to the surface and must be removed promptly to avoid damage to the surface, thus voiding out the warranty. We offer a maintenance agreement, and it is highly recommended to enroll in this program.
LIMITATION OF LIABILITY
Whether attributable to contract, warranty, tort (including negligence), strict liability, or otherwise, Contractor’s responsibility for any claims, damages, losses, or liabilities arising out of or related to its performance of this contract, including but not limited to any correction of defects under the warranty, shall not exceed the cost to correct. In no event shall Contractor be liable for any special, indirect, incidental, consequential, or punitive damages of any character, including but not limited to damages claimed for loss of use of productive facilities or equipment, lost profits, governmental fines or penalties, lost production, or nonoperational or increased expense of operation. This is irrespective of whether claims or actions for such damages are based upon contract, warranty, negligence, strict liability, or otherwise specified.
This Contractor disposes of all waste material in a suitable fashion to include recycling. There will be a $500.00 disposal fee added to the final invoice for proper disposal of all waste material. Customer agrees to an additional fuel surcharge of $35.00 to be added to the final invoice for any job farther than 15 miles from the Contractor’s warehouse location 7011 Wilson Rd. West Palm Beach, FL 33413.
The court area(s) will be closed during the work in progress and will remain closed until the work is complete. It is the Customer’s responsibility to have all irrigation turned off, have no landscaping done while work is in progress within 50 feet of the court surface, and to allow no foot traffic other than Contractor in the work areas while the courts are closed during the work period and 48 hours thereafter. Any damage caused by such intrusions will result in an additional charge to repair the work area solely at the Customer’s expense. It is the Customer’s responsibility to ensure that there is access to the work area and an appropriate power & water source has been identified within 100 feet of the court area(s).
Recycled Asphalt
Recycled asphalt typically works well for tennis/basketball courts. However, there are some instances where deleterious materials can be introduced into the mix during the recycling of old asphalt in the plant. Some of these deleterious materials can be in the form of metals or other oxidants, which can cause stains to appear on the court. Sport Surfaces does not manufacture the recycled asphalt and cannot be held responsible for issues down the road caused by these potential problems. If this is a concern, we recommend going with the upgraded virgin mix design.
By evidence of my signature, I affirm that I have read this contract carefully before signing and having done so, fully agree to be bound by its terms and conditions.
Contract Termination
A sale for future services can be canceled by the buyer by notifying Sport Surfaces LLC within three business days from the date the buyer signed the contract. A written notice sent by mail must be postmarked by no later than midnight of the third business day after the contract date and mailed to 7011 Wilson Rd. West Palm Beach, FL 33413. Due to potential labor shortages, equipment issues, or other unforeseen circumstances, Sport Surfaces LLC reserves the right to cancel a project at any time. In the event of cancellation, Sport Surfaces LLC will refund the customer’s payment, less any costs incurred for work or expenses related to the project.
Owners Responsibilities: New Construction
The court area(s) will be closed during the work in progress and will remain closed until the work is complete. It is the Owner’s responsibility to have all irrigation turned off, to have no landscaping done while work is in progress within 50 feet of the court surface, and no foot traffic other than the contractor in the work areas while the courts are closed during the work period and 48 hours thereafter. Any damage caused by these intrusions may result in damage and additional charges to repair the work area at the owner’s expense. It is the owner’s responsibility to ensure that there is access to the work area and an appropriate power & water source has been identified within 100 feet of the court area(s). For new construction, the customer must provide us with level ground that is +-1″. Most projects in Florida are flat but if major re-grading is required, the daily charge for the equipment and 2 operators will be $1,500/day. Any addition of fill will be charged at $600/load and this includes spreading, laser grading, and compacting fill. The customer must also provide a dumpster for construction debris purposes. Note: the dumpster may need to be emptied and sent back depending on the type of project and all charges associated with disposal are the customer’s responsibility. The customer is to provide stable access to the construction site. We may have to enter the property with concrete, rock, and other heavy construction equipment that can cause damage to driveways, grass, and pavers along with underground pipes/sprinkler systems. While we will do our best to avoid any type of damage, it is impossible for some damage to occur due to the sheer weight of the equipment required to do the work. We are not able to estimate how much damage may or may not occur and therefore have not included any type of repairs associated with this, including the replacement of sod, driveways, pavers, etc. We will level any damaged grass areas and will be able to replace sod at a cost of $750/pallet.
ESCALATION CLAUSE
The Customer acknowledges that inflation is affecting the prices of materials, fuel, and labor. Increases in any of these areas will be subsequently passed onto the customer to cover any increases to Sport Surfaces costs. Should increases in materials, labor, or fuel occur, an email detailing these amounts will be sent out, and this amount will be due to cover these additional costs.
Equipment and Material Storage
It is the customer’s responsibility to provide storage for our equipment, materials, and tools during the construction/resurfacing process. If we are unable to store our equipment, materials, and tools on-site, a storage rental fee + $250 processing fee to find suitable storage will be charged to the customer.
Project Close Out
Sport Surfaces will provide our customers with a (24) hour notice via email along with a telephone call advising you that the project will be closed out the following day. Our project managers shall provide you with a 2-3 hour window where the inspection will take place. It is imperative that either the owner or an owner’s representative is present at that time to walk the project and sign off so that we can demobilize and mobilize to our next project. Note: most of our projects require our crews to stay in hotels and receive a per diem reimbursement which is very costly, making it imperative that we close out projects expediently. For the customer’s convenience, project closeout can be done via WhatsApp or FaceTime video chat. We will provide you with the necessary digital documentation to close out the project and provide you with the necessary warranty. Should punch list items be found, the balance of the contract minus 10% will be due immediately on the initial walk-through. The punch list items will be addressed and corrected, at which time another inspection will be performed under the same terms, and final payment will become due upon acceptance. Should the customer fail to close the job out at the specified time, the job will be considered closed, and if any repairs are required, a $750 callback fee will be charged to cover re-mobilization costs.
Disputes
Notwithstanding any provision contained in any Contract Documents requiring arbitration, both parties agree that any specific dispute under this contract with a claim less than $150,000.00 shall be submitted to arbitration in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association, upon Contractor’s election. Each such dispute which is submitted to arbitration shall be heard before the American Arbitration Association in the State, which shall be West Palm Beach, Florida, in the case of projects located in Florida or states served by the West Palm Beach office of the American Arbitration Association, unless the Contractor and Subcontractor agree on some other location. All disputes (single or aggregate) which exceed $250,000.00 or where injunctive relief is sought shall be decided by a court of competent jurisdiction, and trial by jury is expressly waived. The parties agree, upon Contractor’s written demand, to become a party to and be bound by any arbitration proceeding involving the Contractor, the Architect, or the Owner to the extent that such proceedings involve any of the rights or obligations of the parties under this contract. Parties agree to attempt in good faith to resolve any dispute arising out of or relating to this contract by non-binding mediation with a mediator mutually agreed to by the parties. Mediation shall be initiated by a written request from either party to the other specifying the dispute(s) to be mediated. Such mediation shall be a condition precedent to the commencement of litigation or arbitration, unless delay would irrevocably prejudice either party, in which event the litigation or arbitration, as the case may be, may be commenced but shall be stayed pending mediation under this provision. If the dispute has not been resolved pursuant to the mediation procedure within 30 days of the commencement of such procedure, which shall mean the first joint session with the mediator, the dispute shall be determined in accordance with the provisions of the first paragraph of this section. The fees and expenses of the mediator shall be borne equally by both parties.
Anti-Poaching Agreement
WHEREAS, the Company is engaged in the business of sports construction, including but not limited to the installation, repairs, and maintenance of sports surfaces: including but not limited to tennis, pickleball, bocce ball, basketball, volleyball, soccer, padel, and hockey courts.
WHEREAS, the Customer desires to engage the Company for its services; and
WHEREAS, the Company has invested considerable time and resources in training its employees, crews, and subcontractors.
NOW, THEREFORE, in consideration of the mutual covenants and agreements herein contained, the parties hereto agree as follows:
Non-Solicitation of Employees, Crews, and Subcontractors 1.1. During the term of this Agreement and for a period of thirty-six (36) months following the termination or expiration of this Agreement, the Customer agrees not to directly or indirectly solicit, hire, or engage any employee, crew member, or subcontractor of the Company without the prior written consent of the Company. 1.2. The Customer agrees not to encourage or induce any employee, crew member, or subcontractor of the Company to terminate their relationship with the Company.
Confidentiality 2.1. The Customer acknowledges that during the course of the business relationship with the Company, it may have access to confidential and proprietary information about the Company’s employees, crews, and subcontractors. The Customer agrees to keep all such information confidential and not to disclose it to any third party without the prior written consent of the Company. 2.2. This confidentiality obligation shall survive the termination or expiration of this Agreement.
Remedies 3.1. The Customer acknowledges that any breach of this Agreement may cause irreparable harm to the Company and that monetary damages may not be sufficient to compensate the Company. Accordingly, the Customer agrees that the Company shall be entitled to seek injunctive relief in addition to any other remedies available at law or in equity. 3.2. In the event of a breach of this Agreement, the Customer agrees to reimburse the Company for any and all losses, damages, costs, and expenses (including reasonable attorney’s fees) incurred by the Company as a result of such breach.
Miscellaneous 4.1. Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of Florida. 4.2. Severability. If any provision of this Agreement is found to be invalid or unenforceable, the remaining provisions shall continue in full force and effect. 4.3. Entire Agreement. This Agreement constitutes the entire agreement between the parties and supersedes all prior understandings or agreements, whether written or oral, regarding the subject matter herein. 4.4. Amendments. This Agreement may be amended only in writing signed by both parties. 4.5. Waiver. The failure of either party to enforce any provision of this Agreement shall not be deemed a waiver of such provision or of the right to enforce it at a later time. 4.6. Assignment. This Agreement shall not be assigned by the Customer without the prior written consent of the Company.
Privacy Policy
Sport Surfaces LLC strongly believes in protecting the privacy of your data, the personally identifiable information you share with us, and respecting the permission you give us to use that information. This Privacy Policy notifies you of our privacy practices, describes how we will use your information, and describes the choices you have concerning how your information is collected and used. This will make it easier for you to:
- Request information from Sport Surfaces specific to your interests;
- Receive personalized messages to your specific questions;
- Save time by storing your preferences;
- Utilize web site-based services; and
- Allow us to conduct market research to help us improve our products, our services, and our websites.
We will only collect, use, or share your personally identifiable information if you give us permission to do so. Financial information provided by you is used solely to transact payments as you arrange through the use of Services provided by a particular website. For example, by arranging a rental payment, completing your application form, sending us an email, or utilizing other services that may be available through a particular website, you are giving us permission to use and share your non-financial information. You should know that by filling out your application form, sending us an email, or other utilization of website services, you are giving Sport Surfaces permission to transfer your personally identifiable information among the Sport Surfaces company to fulfill your requirement. However, we will not share any information you provide with other non-affiliated companies.
We use commercially reasonable means to minimize the risk of unauthorized disclosures of your data and personally identifiable information, including restricting access to your data and personally identifiable information to those employees who need to know that information to provide and fulfill services to you. We maintain appropriate physical, electronic, procedural, and managerial safeguards to help prevent unauthorized access to the information. We may disclose information as required by law.
In general, you can visit the Sport Surfaces LLC sites without telling us who you are or revealing any information about yourself. Our web servers collect domain email addresses of visitors. This information is aggregated to measure the average time spent on the site and pages viewed. Sport Surfaces LLC uses this information to see the use of our websites and improve our websites’ content.
If you would like to contact us for any reason regarding our Privacy Policy, you may do so via the “Contact” page on this website or by mailing to:
:Licensing and Permits:
Ability to Opt Out from Receiving Certain Communications
You have the choice to opt out of receiving certain marketing communications (email or text messages) you might receive from Sport Surfaces (the “Sender”). Normally, a marketing email you receive from Sport Surfaces will have an opt-out link provided within the email itself (usually toward the bottom), and you can opt out of receiving further such marketing emails by clicking on the link and indicating your decision.
If you receive marketing texts from Sport Surfaces, you can opt out of receiving further such texts by following the instructions provided in the text itself — often by replying “STOP” — or by emailing us at stop@sportsurfaces.com and including enough information for us to properly process your request (e.g., your full name, your complete phone number with area code, and an image or description of the marketing text you received). Whether it’s email or text, your request will be handled promptly; however, please note that for a reasonable time you might still receive some marketing emails or texts while your request is being processed.
Note also that opting out of marketing emails or texts will not necessarily stop you from receiving non-marketing messages, such as communications about a purchase you have made, a transaction you have with Sport Surfaces, project updates, appointment reminders, or other administrative and informational notices. Some or all of these kinds of messages (especially texts) may also be discontinued at our discretion.
Additional SMS Program Details
-
Message and data rates may apply.
-
Message frequency may vary and could be recurring depending on the program.
-
Text “STOP” in reply to any marketing text from Sport Surfaces to stop receiving further such texts (see above for additional details).
-
Text “HELP” in reply to any marketing text from Sport Surfaces to request help or assistance.
-
Example of a program’s sponsor or Sender: SportSurfaces.com
-
Texts may include both marketing and non-marketing communications.
-
Carriers disclaim liability for delayed or undelivered messages.
Disclaimer Regarding Fees and Services
This fee does not include, and our services do not cover, the following unless expressly agreed upon in writing:
- Architectural design or preparation of plans
- Zoning actions, land use amendments, or platting
- Board of adjustment requests or any public appearances
- Environmental studies, reports, or assessments
- Structural design or geotechnical analysis
- Survey work or related activities
- Landscape and irrigation plans, including landscaping consultants
- Photometric plans or lighting analysis
- Florida Department of Environmental Protection (FDEP) water and sewer permitting
- Impact fees or assessments
- Signage design, fabrication, or permitting
- Transportation analysis or traffic studies
- Off-site drainage studies or roadway improvement designs
- Fire line calculations or fire protection system design
- Reimbursable expenses such as printing, facsimiles, telephone charges, courier services, etc.
- Permit application fees or any fees required by regulatory agencies for project approval
The client will be responsible for any additional fees or services not explicitly covered under this agreement. Any services required outside the scope of this fee structure will be billed separately.
Sport Surfaces LLC
7011 Wilson Rd.
West Palm Beach, FL. 33413
We reserve the right to change this policy at any time by posting a new Privacy Policy as well as a terms and conditions policy. We advise our customer to check for updates.
Contact Us
